Va code 11-4.1:1 – Construction Law Musings- Richmond, VA

Remember BAE Systems and Fluor? This post is the third here at Construction Law Musings relating to this case which is a seemingly never-ending source for content. In the prior post discussing this case, the Court found that Va. Code 1-4.1:1 which bars waiver of a right to payment before work is performed did not apply because Fluor had provided work before execution of the contract or any change orders.

In the most recent opinion in this long-running litigation, and after a motion to reconsider by Fluor that was granted, the Court re-examined this finding along with the contractual language found in the Limitation of Damages (LOD) clause and came to the opposite conclusion regarding certain change orders that remained unpaid by BAE. Continue reading Are Construction Contract Limitation of Liability Clauses on the Way Out in Virginia?

qimono @ Pixabay Anyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute.

The recent case out of the Eastern District of Virginia federal court, Strata Solar LLC v. Fall Line Construction LLC, added a bit of clarity. Continue reading No Damages for Delay May Not Be Enforceable in Virginia