Thoughts on construction law from Christopher G. Hill, Virginia construction lawyer, LEED AP, mediator, and member of the Virginia Legal Elite in Construction Law
Previously in this on-again-off-again series of posts on construction contract basics, I discussed attorney fees provisions and indemnification. In this installment, the topic at hand is venue and choice of law.
As construction professionals (outside of us construction attorneys), you are likely to be focused on things like the scope of work in a construction contract, the price terms, payment, delays, change orders, and the like. However, the venue (where any lawsuit or arbitration will have to happen) and the choice of law (what state’s law applies) can be equally important. You need to know where you will have to enforce your rights under the contract and also what law will apply. Will you need to go to another state to enforce your rights? Even if not, will your local attorney have to learn the law of another jurisdiction? These are important questions when reading and negotiating your prime contract (if with the owner) or subcontract (if with the general contractor). Continue reading Construction Contract Basics: Venue and Choice of Law
Map of Virginia highlighting Loudoun County (Photo credit: Wikipedia)
Here at Construction Law Musings, we’ve discussed the fact that, in Virginia, the “economic loss rule” generally renders claims of fraud and construction contracts like oil and water. This is true in most states, including Florida.
What this means is that as a general rule where any party is supposed to perform under a contract, and fails to do so, the Virginia courts will dismiss a fraud claim out of a desire to avoid turning any breach of contract (read “broken promise”) case into a claim for fraud. As you have likely gathered by the title of this post, there are exceptions. One is a properly plead Virginia Consumer Protection Act (“VCPA”) claim.
In it’s opinion, the 4th Circuit looked at some of the more “interesting” aspects of this case. One of these circumstances was that Syska (the general contractor) directed Aarow to construct sedimentary ponds and other water management measures around the project (the “pond work”), which both agreed was outside of the scope of the work defined in their subcontract. Syska asked that the government agree to a modification of the prime contract and asked Aarow to wait to submit its invoice for the pond work until after the government issued a modification to the prime contract and Syska issued a change order to the subcontract.
Several months later, no modification or change order had been issued, and Aarow submitted an invoice to Syska for the completed pond work. Syska instructed Aarow to list the pond work under a line item designated for certain finishing work on the project that had not yet been completed. The government denied the subsequent change order request (submitted by Syska), stating that the pond work was in the scope of the original contract and Syska withheld money owed for other aspects of the work to make up the difference for the previously billed pond work.
Anyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute.
